CIVIL LIABILITY
Section 67. Civil Liability in Case of Conviction
Without prejudice to administrative sanctions that may be imposed in proper cases, a conviction under the Act and this IRR or R.A. 3019 shall carry with it civil liability, which may either consist of restitution for the damage done or the forfeiture in favor of the government of any unwarranted benefit derived from the act or acts in question, or both, at the discretion of the courts.
Section 68. Liquidated Damages
All contracts executed in accordance with the Act and this IRR shall contain a provision on liquidated damages which shall be payable by the contractor in case of breach thereof. For the procurement of Goods, Infrastructure Projects and Consulting Services, the amount of the liquidated damages shall be at least equal to one-tenth of one percent (0.001) of the cost of the unperformed portion for every day of delay. Once the cumulative amount of liquidated damages reaches ten percent (10%) of the amount of the contract, the Procuring Entity may rescind or terminate the contract, without prejudice to other courses of action and remedies available under the circumstances.